About GPO   |   Newsroom/Media   |   Congressional Relations   |   Inspector General   |   Careers   |   Contact   |   askGPO   |   Help  
 
Home   |   Customers   |   Vendors   |   Libraries  

The Electronic Code of Federal Regulations (e-CFR) is a regularly updated, unofficial editorial compilation of CFR material and Federal Register amendments produced by the National Archives and Records Administration's Office of the Federal Register (OFR) and the Government Printing Office.

Parallel Table of Authorities and Rules for the Code of Federal Regulations and the United States Code
Text | PDF

Find, review, and submit comments on Federal rules that are open for comment and published in the Federal Register using Regulations.gov.

Purchase individual CFR titles from the U.S. Government Online Bookstore.

Find issues of the CFR (including issues prior to 1996) at a local Federal depository library.

[2]
 
 

Electronic Code of Federal Regulations

e-CFR Data is current as of September 29, 2014

Title 48Chapter 2Subchapter F → Part 236


Title 48: Federal Acquisition Regulations System


PART 236—CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS


Contents

Subpart 236.1—General

236.102   Definitions.

Subpart 236.2—Special Aspects of Contracting for Construction

236.203   Government estimate of construction costs.
236.204   Disclosure of the magnitude of construction projects.
236.206   Liquidated damages.
236.213   Special procedures for sealed bidding in construction contracting.
236.270   Expediting construction contracts.
236.271   Cost-plus-fixed-fee contracts.
236.272   Prequalification of sources.
236.273   Construction in foreign countries.
236.274   Restriction on acquisition of steel for use in military construction projects.
236.275   Construction of industrial resources.

Subpart 236.5—Contract Clauses

236.570   Additional provisions and clauses.

Subpart 236.6—Architect-Engineer Services

§236.601   Policy
236.602   Selection of firms for architect-engineer contracts.
236.602-1   Selection criteria.
236.602-70   Restriction on award of overseas architect-engineer contracts to foreign firms.
236.604   Performance evaluation.
236.606   Negotiations.
236.606-70   Statutory fee limitation.
236.609   Contract clauses.
236.609-70   Additional provision and clause.

Subpart 236.7—Standard and Optional Forms for Contracting for Construction, Architect-Engineer Services, and Dismantling, Demolition, or Removal of Improvements

236.701   Standard and optional forms for use in contracting for construction or dismantling, demolition, or removal of improvements.

Authority: 41 U.S.C. 421 and 48 CFR chapter 1.

Source: 56 FR 36421, July 31, 1991, unless otherwise noted.

Subpart 236.1—General

236.102   Definitions.

Construction activity means an activity at any organizational level of the DoD that—

(1) Is responsible for the architectural, engineering, and other related technical aspects of the planning, design, and construction of facilities; and

(2) Receives its technical guidance from the Army Office of the Chief of Engineers, Naval Facilities Engineering Command, or Air Force Directorate of Civil Engineering.

Marshallese firm is defined in the provision at 252.236-7012, Military Construction on Kwajalein Atoll—Evaluation Preference.

United States firm is defined in the provisions at 252.236-7010, Overseas Military Construction-Preference for United States Firms, and 252.236-7011, Overseas Architect-Engineer Services-Restriction to United States firms.

[56 FR 36421, July 31, 1991, as amended at 62 FR 2857, Jan. 17, 1997; 63 FR 11538, Mar. 9, 1998; 71 FR 9272, Feb. 23, 2006; 76 FR 58155, Sept. 20, 2011]

Subpart 236.2—Special Aspects of Contracting for Construction

236.203   Government estimate of construction costs.

Follow the procedures at PGI 236.203 for handling the Government estimate of construction costs.

[71 FR 9273, Feb. 23, 2006]

236.204   Disclosure of the magnitude of construction projects.

Additional price ranges are—

(i) Between $10,000,000 and $25,000,000;

(ii) Between $25,000,000 and $100,000,000;

(iii) Between $100,000,000 and $250,000,000;

(iv) Between $250,000,000 and $500,000,000; and

(v) Over $500,000,000.

[61 FR 7749, Feb. 29, 1996]

236.206   Liquidated damages.

See 211.503 for instructions on use of liquidated damages.

[56 FR 36421, July 31, 1991, as amended at 66 FR 49861, Oct. 1, 2001]

236.213   Special procedures for sealed bidding in construction contracting.

If it appears that sufficient funds may not be available for all the desired construction features, consider using a bid schedule with additive or deductive items in accordance with PGI 236.213.

[71 FR 9273, Feb. 23, 2006]

236.270   Expediting construction contracts.

(a) 10 U.S.C. 2858 requires agency head approval to expedite the completion date of a contract funded by a Military Construction Appropriations Act, if additional costs are involved. This approval authority may not be redelegated. The approval authority must—

(1) Certify that the additional expenditures are necessary to protect the National interest; and

(2) Establish a reasonable completion date for the project.

(b) The contracting officer may approve an expedited completion date if no additional costs are involved.

236.271   Cost-plus-fixed-fee contracts.

Annual military construction appropriations acts restrict the use of cost-plus-fixed-fee contracts (see 216.306(c)).

[61 FR 7749, Feb. 29, 1996]

236.272   Prequalification of sources.

(a) Prequalification procedures may be used when necessary to ensure timely and efficient performance of critical construction projects. Prequalification—

(1) Results in a list of sources determined to be qualified to perform a specific construction contract; and

(2) Limits offerors to those with proven competence to perform in the required manner.

(b) The head of the contracting activity must—

(1) Authorize the use of prequalification by determining, in writing, that a construction project is of an urgency or complexity that requires prequalification; and

(2) Approve the prequalification procedures.

(c) For small businesses, the prequalification procedures must require the qualifying authority to—

(1) Request a preliminary recommendation from the appropriate Small Business Administration regional office, if the qualifying authority believes a small business is not responsible;

(2) Permit the small business to submit a bid or proposal if the preliminary recommendation is that the small business is responsible; and

(3) Follow the procedures in FAR 19.6, if the small business is in line for award and is found nonresponsible.

236.273   Construction in foreign countries.

(a) In accordance with section 112 of the Military Construction and Veterans Affairs and Related Agencies Appropriations Act, 2014 (Division J of Pub. L. 113-76) and similar sections in subsequent military construction appropriations acts, military construction contracts funded with military construction appropriations, that are estimated to exceed $1,000,000 and are to be performed in the United States outlying areas in the Pacific and on Kwajalein Atoll, or in countries bordering the Arabian Sea (i.e., India, Iran, Oman, Pakistan, Somalia, and Yemen)], shall be awarded only to United States firms, unless—

(1) The lowest responsive and responsible offer of a United States firm exceeds the lowest responsive and responsible offer of a foreign firm by more than 20 percent; or

(2) The contract is for military construction on Kwajalein Atoll and the lowest responsive and responsible offer is submitted by a Marshallese firm.

(b) See PGI 236.273(b) for guidance on technical working agreements with foreign governments.

[56 FR 36421, July 31, 1991, as amended at 62 FR 2856, Jan. 17, 1997; 62 FR 34127, June 24, 1997; 63 FR 11538, Mar. 9, 1998; 66 FR 49861, Oct. 1, 2001; 70 FR 35545, June 21, 2005. Redesignated and amended at 71 FR 9273, Feb. 23, 2006; 79 FR 44316, July 31, 2014]

236.274   Restriction on acquisition of steel for use in military construction projects.

In accordance with section 108 of the Military Construction and Veterans Affairs Appropriations Act, 2009 (Pub. L. 110-329, Division E), do not acquire, or allow a contractor to acquire, steel for any construction project or activity for which American steel producers, fabricators, or manufacturers have been denied the opportunity to compete for such acquisition of steel.

[74 FR 2418, Jan. 15, 2009]

236.275   Construction of industrial resources.

See Subpart 237.75 for policy relating to facilities projects.

[74 FR 37646, July 29, 2009]

Subpart 236.5—Contract Clauses

236.570   Additional provisions and clauses.

(a) Use the following clauses in all fixed-price construction solicitations and contracts—

(1) 252.236-7000, Modification Proposals-Price Breakdown; and

(2) 252.236-7001, Contract Drawings and Specifications.

(b) Use the following provisions and clauses in fixed-price construction contracts and solicitations as applicable—

(1) 252.236-7002, Obstruction of Navigable Waterways, when the contract will involve work near or on navigable waterways.

(2) When the head of the contracting activity has approved use of a separate bid item for mobilization and preparatory work, use either—

(i) 252.236-7003, Payment for Mobilization and Preparatory Work. Use this clause for major construction contracts that require—

(A) Major or special items of plant and equipment; or

(B) Large stockpiles of material which are in excess of the type, kind, and quantity which would be normal for a contractor qualified to undertake the work; or

(ii) 252.236-7004, Payment for Mobilization and Demobilization. Use this clause for contracts involving major mobilization expense, or plant equipment and material (other than the situations covered in paragraph (b)(2)(i) of this section) made necessary by the location or nature of the work.

(A) Generally, allocate 60 percent of the lump sum price in paragraph (a) of the clause to the cost of mobilization.

(B) Vary this percentage to reflect the circumstances of the particular contract, but in no event should mobilization exceed 80 percent of the payment item.

(3) 252.236-7005, Airfield Safety Precautions, when construction will be performed on or near airfields.

(4) 252.236-7006, Cost Limitation, if the solicitation's bid schedule contains one or more items subject to statutory cost limitations, and if a waiver has not been granted (FAR 36.205).

(5) 252.236-7007, Additive or Deductive Items, if the procedures in 236.213 are being used.

(6) 252.236-7008, Contract Prices—Bidding Schedule, if the contract will contain only unit prices for some items.

(c) Use the following provisions in solicitations for military construction contracts that are funded with military construction appropriations and are estimated to exceed $1,000,000:

(1) 252.236-7010, Overseas Military Construction—Preference for United States Firms, when contract performance will be in a United States outlying area in the Pacific or in a country bordering the Arabian Sea.

(2) 252.236-7012, Military Construction on Kwajalein Atoll—Evaluation Preference, when contract performance will be on Kwajalein Atoll.

(d) Use the clause at 252.236-7013, Requirement for Competition Opportunity for American Steel Producers, Fabricators, and Manufacturers, in solicitations and contracts that—

(1) Use funds appropriated by Title I of the Military Construction and Veterans Affairs Appropriations Act, 2009 (Pub. L. 110-329, Division E); and

(2) May require the acquisition of steel as a construction material.

(e) Also see 246.710(4) for an additional clause applicable to construction contracts to be performed in Germany.

[56 FR 36421, July 31, 1991, as amended at 57 FR 42632, Sept. 15, 1992; 62 FR 2856, Jan. 17, 1997; 62 FR 34127, June 24, 1997; 63 FR 11538, Mar. 9, 1998; 65 FR 63804, Oct. 25, 2000; 68 FR 7440, Feb. 14, 2003; 70 FR 35545, June 21, 2005; 73 FR 46817, Aug. 12, 2008; 74 FR 2418, Jan. 15, 2009; 79 FR 44316, July 31, 2014]

Subpart 236.6—Architect-Engineer Services

§236.601   Policy

(1) Written notification to the congressional defense committees is required if the total estimated contract price for architect-engineer services or construction design, in connection with military construction, military family housing, or restoration or replacement of damaged or destroyed facilities, exceeds $1,000,000. In accordance with 10 U.S.C. 480, unclassified notifications must be provided by electronic medium.

(i) For military construction or military family housing (10 U.S.C. 2807(b)), the notification—

(A) Must include the scope of the project and the estimated contract price; and

(B)(1) If provided by electronic medium, must be provided at least 14 days before the initial obligation of funds; or

(2) If provided by other than electronic medium, must be received by the congressional defense committees at least 21 days before the initial obligation of funds.

(ii) For restoration or replacement of damaged or destroyed facilities (10 U.S.C. 2854(b)), the notification—

(A) Must include the justification for the project, the estimated contract price, and the source of the funds for the project; and

(B)(1) If provided by electronic medium, must be provided at least 7 days before the initial obligation of funds; or

(2) If provided by other than electronic medium, must be received by the congressional defense committees at least 21 days before the initial obligation of funds.

(2) During the applicable notice period, synopsis of the proposed contract action and administrative actions leading to the award may be started.

[71 FR 58541, Oct. 4, 2006]

236.602   Selection of firms for architect-engineer contracts.

236.602-1   Selection criteria.

(a) Establish the evaluation criteria before making the public announcement required by FAR 5.205(d) and include the criteria and their relative order of importance in the announcement. Follow the procedures at PGI 236.602-1(a).

[69 FR 75000, Dec. 15, 2004, as amended at 71 FR 53044, Sept. 8, 2006]

236.602-70   Restriction on award of overseas architect-engineer contracts to foreign firms.

In accordance with section 111 of the Military Construction and Veterans Affairs and Related Agencies Appropriations Act, 2014 (Division J of Pub. L. 113-76) and similar sections in subsequent military construction appropriations acts, architect-engineer contracts funded by military construction appropriations that are estimated to exceed $500,000 and are to be performed in Japan, in any North Atlantic Treaty Organization member country, or in countries bordering the Arabian Sea (i.e., India, Iran, Oman, Pakistan, Somalia, and Yemen), shall be awarded only to United States firms or to joint ventures of United States and host nation firms.

[79 FR 44316, July 31, 2014]

236.604   Performance evaluation.

Prepare a separate performance evaluation after actual construction of the project. Ordinarily, the evaluating official should be the person most familiar with the architect-engineer contractor's performance.

[76 FR 58155, Sept. 20, 2011]

236.606   Negotiations.

236.606-70   Statutory fee limitation.

(a) 10 U.S.C. 4540, 7212, and 9540 limit the contract price (or fee) for architect-engineer services for the preparation of designs, plans, drawings, and specifications to six percent of the project's estimated construction cost.

(b) The six percent limit also applies to contract modifications, including modifications involving—

(1) Work not initially included in the contract. Apply the six percent limit to the revised total estimated construction cost.

(2) Redesign. Apply the six percent limit as follows—

(i) Add the estimated construction cost of the redesign features to the original estimated construction cost;

(ii) Add the contract cost for the original design to the contract cost for redesign; and

(iii) Divide the total contract design cost by the total estimated construction cost. The resulting percentage may not exceed the six percent statutory limitation.

(c) The six percent limit applies only to that portion of the contract (or modification) price attributable to the preparation of designs, plans, drawings, and specifications. If a contract or modification also includes other services, the part of the price attributable to the other services is not subject to the six percent limit.

[56 FR 36421, July 31, 1991, as amended at 76 FR 58156, Sept. 20, 2011]

236.609   Contract clauses.

236.609-70   Additional provision and clause.

(a)(1) Use the clause at 252.236-7009, Option for Supervision and Inspection Services, in solicitations and contracts for architect-engineer services when—

(i) The contract will be fixed price; and

(ii) Supervision and inspection services by the architect-engineer may be required during construction.

(2) Include the scope of such services in appendix A of the contract.

(b) Use the provision at 252.236-7011, Overseas Architect-Engineer Services—Restriction to United States Firms, in solicitations for architect-engineer contracts that are—

(1) Funded with military construction appropriations;

(2) Estimated to exceed $500,000; and

(3) To be performed in Japan, in any North Atlantic Treaty Organization member country, or in countries bordering the Arabian Sea.

[56 FR 36421, July 31, 1991, as amended at 62 FR 2858, Jan. 17, 1997; 63 FR 11539, Mar. 9, 1998; 76 FR 58156, Sept. 20, 2011; 79 FR 44316, July 31, 2014]

Subpart 236.7—Standard and Optional Forms for Contracting for Construction, Architect-Engineer Services, and Dismantling, Demolition, or Removal of Improvements

236.701   Standard and optional forms for use in contracting for construction or dismantling, demolition, or removal of improvements.

(c) Do not use Optional Form 347, Order for Supplies or Services (see 213.307).

[56 FR 36421, July 31, 1991, as amended at 65 FR 63804, Oct. 25, 2000]



For questions or comments regarding e-CFR editorial content, features, or design, email ecfr@nara.gov.
For questions concerning e-CFR programming and delivery issues, email webteam@gpo.gov.